Semi-Submersible

  • North Sea
A Semi-Submersible brown field project, consisting of the conversion of a large exploration vessel to a production vessel overran in time and in money. As expected in the conversion of a 25 year old structure that has spent its life at sea, many variations and changes were required that had not been foreseen after the initial survey. Weather, changes and general delays led to a significant dispute. Appointed as experts in quantum the role was to present an independent report to the Tribunal. Once the expert report was produced the claimant conceded sufficient elements of their claim that a settlement for a third of the initial claim was agreed.

USA

LNG Plant

A named windstorm caused widespread damage to the construction of an LNG plant.

Europe

187MW Hydro Power Plant

Following the collapse of the project’s headrace tunnel, CCi was appointed as the delay expert to produce an analysis that would eventually facilitate a mediated settlement.

Tamworth, Australia

Tamworth 330KV Capacitor Banks and SVC Works

CCi was engaged by the Subcontractor responsible for all civil and concrete works, to assess the contractual position in terms of extension of time entitlement and to produce a consolidated extension of time along with associated costs claim.

Australia

Airport Link Motorway

It was claimed that seven separate events had caused critical delay to the project’s completion date.